Name
Contact Number
Email
Tell us what you’re interested in
Terms and Conditions for Consumers
Effective Date: 12 November 2025
This document sets out the terms under which Southern Cross Saunas, operated by David Andrews as a sole trader (ABN 32 115 032 815) (“Southern Cross Saunas”, “we”, “our”, or “us”), provides products and installation services to its customers (“you”, “your”).
By paying a deposit, signing a quote, or confirming an order, you agree to these Terms and Conditions. Please read them carefully and keep a copy for your records.
1. Our Commitment
We take pride in providing high-quality saunas and services made in Australia.
We aim to deliver work using reasonable care, skill, and materials suitable for their intended purpose, in line with Australian Consumer Law.
2. Quotes and Orders
A Quote outlines the estimated cost of your sauna, including delivery and installation.
A binding contract is formed once the Quote is approved in writing or a deposit is paid.
Any changes to design, specifications, or materials requested after approval may result in adjustments to the final price and/or delivery timeline
We recommend reviewing all details before confirming your order.
3. Deposits and Payments
A 50% deposit is payable upon approval of the quote to secure your sauna in our workshop schedule and planning work.
A 50% final payment on the day of installation unless alternative payment terms have been agreed in writing by both parties.
All prices include GST unless stated otherwise.
Ownership of all goods remains with Southern Cross Saunas until full payment is received.
4. Delivery and Installation
We will confirm an estimated delivery and installation date once full payment has cleared.
Delivery times may vary due to weather, supplier delays, or freight issues — we will keep you informed.
Before installation, you are responsible for ensuring:
Safe and accessible site conditions;
Any required council approvals or permits;
Access to electricity, flat ground, and clear working space.
If installation is delayed because the site is not ready, additional charges may apply.
5. Quality and Warranty
Your sauna comes with the consumer guarantees required under Australian law.
This means it will be:
Of acceptable quality;
Fit for purpose; and
Match its description.
If your sauna has a defect, we will repair, replace, or refund it as required under the Australian Consumer Law.
Damage caused by misuse, poor maintenance, or unauthorised modification is not covered.
6. Cancellations and Refunds
After production begins, cancellations may incur charges for work or materials already ordered.
If we agree to a cancellation, we will deduct reasonable costs before refunding any balance.
If you believe our products or services don’t meet legal guarantees, please contact us immediately so we can resolve the issue quickly and fairly.
7. Delays and Events Outside Our Control
Sometimes unforeseen events (for example, extreme weather, supplier shortages, illness, or transport delays) may affect delivery or installation.
We will always do our best to minimise delays and keep you informed, but we are not liable for delays caused by factors beyond our control.
8. Your Responsibilities
You agree to:
Provide accurate information and measurements;
Prepare the site according to our guidance;
Give us reasonable access to complete delivery and installation;
Comply with safety instructions provided.
We are not responsible for damage caused by inaccurate site information or pre-existing structural issues.
9. Intellectual Property
All plans, designs, and materials we provide remain the property of Southern Cross Saunas.
They may not be reproduced or shared without our written permission.
10. Communication
We primarily communicate via email.
All formal correspondence should be sent to:
info@southerncrosssaunas.com.au
We may contact you by phone or email to provide updates, arrange delivery, or clarify details of your order.
11. Liability
Our liability to you is limited to what is required under Australian Consumer Law.
We are not responsible for:
Loss of profit, income, or opportunity;
Delays due to circumstances beyond our control;
Minor variations in timber colour or natural grain, as these are inherent to the product.
We do not exclude or limit liability for injury, negligence, or wilful misconduct.
12. Governing Law
These Terms and Conditions are governed by the laws of New South Wales, Australia.
Any disputes shall be resolved in the courts of New South Wales.
13. Contact Us
If you have any questions, concerns, or wish to make a complaint, please contact:
Southern Cross Saunas
Operated by David Andrews, Sole Trader (ABN 32 115 032 815)
Email: info@southerncrosssaunas.com.au
Address: 66 Swan Street, Morpeth NSW 2321
Phone: 0297352363
Effective Date: 12 November 2025
This document sets out the terms under which Southern Cross Saunas, operated by David Andrews as a sole trader (ABN 32 115 032 815) (“Southern Cross Saunas”, “we”, “our”, or “us”), provides products and installation services to its customers (“you”, “your”).
By paying a deposit, signing a quote, or confirming an order, you agree to these Terms and Conditions. Please read them carefully and keep a copy for your records.
1. Our Commitment
We take pride in providing high-quality saunas and services made in Australia.
We aim to deliver work using reasonable care, skill, and materials suitable for their intended purpose, in line with Australian Consumer Law.
2. Quotes and Orders
A Quote outlines the estimated cost of your sauna, including delivery and installation.
A binding contract is formed once the Quote is approved in writing or a deposit is paid.
Any changes to design, specifications, or materials requested after approval may result in adjustments to the final price and/or delivery timeline
We recommend reviewing all details before confirming your order.
3. Deposits and Payments
A 50% deposit is payable upon approval of the quote to secure your sauna in our workshop schedule and planning work.
A 50% final payment on the day of installation unless alternative payment terms have been agreed in writing by both parties.
All prices include GST unless stated otherwise.
Ownership of all goods remains with Southern Cross Saunas until full payment is received.
4. Delivery and Installation
We will confirm an estimated delivery and installation date once full payment has cleared.
Delivery times may vary due to weather, supplier delays, or freight issues — we will keep you informed.
Before installation, you are responsible for ensuring:
Safe and accessible site conditions;
Any required council approvals or permits;
Access to electricity, flat ground, and clear working space.
If installation is delayed because the site is not ready, additional charges may apply.
5. Quality and Warranty
Your sauna comes with the consumer guarantees required under Australian law.
This means it will be:
Of acceptable quality;
Fit for purpose; and
Match its description.
If your sauna has a defect, we will repair, replace, or refund it as required under the Australian Consumer Law.
Damage caused by misuse, poor maintenance, or unauthorised modification is not covered.
6. Cancellations and Refunds
After production begins, cancellations may incur charges for work or materials already ordered.
If we agree to a cancellation, we will deduct reasonable costs before refunding any balance.
If you believe our products or services don’t meet legal guarantees, please contact us immediately so we can resolve the issue quickly and fairly.
7. Delays and Events Outside Our Control
Sometimes unforeseen events (for example, extreme weather, supplier shortages, illness, or transport delays) may affect delivery or installation.
We will always do our best to minimise delays and keep you informed, but we are not liable for delays caused by factors beyond our control.
8. Your Responsibilities
You agree to:
Provide accurate information and measurements;
Prepare the site according to our guidance;
Give us reasonable access to complete delivery and installation;
Comply with safety instructions provided.
We are not responsible for damage caused by inaccurate site information or pre-existing structural issues.
9. Intellectual Property
All plans, designs, and materials we provide remain the property of Southern Cross Saunas.
They may not be reproduced or shared without our written permission.
10. Communication
We primarily communicate via email.
All formal correspondence should be sent to:
info@southerncrosssaunas.com.au
We may contact you by phone or email to provide updates, arrange delivery, or clarify details of your order.
11. Liability
Our liability to you is limited to what is required under Australian Consumer Law.
We are not responsible for:
Loss of profit, income, or opportunity;
Delays due to circumstances beyond our control;
Minor variations in timber colour or natural grain, as these are inherent to the product.
We do not exclude or limit liability for injury, negligence, or wilful misconduct.
12. Governing Law
These Terms and Conditions are governed by the laws of New South Wales, Australia.
Any disputes shall be resolved in the courts of New South Wales.
13. Contact Us
If you have any questions, concerns, or wish to make a complaint, please contact:
Southern Cross Saunas
Operated by David Andrews, Sole Trader (ABN 32 115 032 815)
Email: info@southerncrosssaunas.com.au
Address: 66 Swan Street, Morpeth NSW 2321
Phone: 0297352363
Terms and Conditions for Business Clients
Effective Date: 12 November 2025
This agreement sets out the terms under which Southern Cross Saunas, operated by David Andres as a sole trader (ABN 32 115 032 815) (“Southern Cross Saunas”, “we”, “our”, or “us”), provides products and installation services to commercial clients (“you”, “your”).
By accepting a quote, paying a deposit, or confirming an order, you agree to these Terms and Conditions.
1. Scope of Agreement
These Terms apply to all goods and services supplied by Southern Cross Saunas to business customers, including the manufacture, delivery, and installation of saunas or related products.
If you are purchasing as a consumer, our Consumer Terms and Conditions will apply instead.
2. Quotes and Contracts
A Quote outlines the estimated cost of your project, including design, materials, and installation.
Once you approve the quote in writing or pay a deposit, a binding contract is formed.
A detailed Order Confirmation Form will confirm the final specifications and pricing.
Changes requested after approval may affect cost and delivery timelines.
We encourage you to carefully review the quote before proceeding.
3. Deposits and Payments
Payment is made in stages as follows:
40% deposit – payable upon acceptance of the Quote. This deposit becomes non-refundable once procurement of materials or design and engineering work has commenced.
30% progress payment – payable upon commencement of production.
30% final payment – payable prior to delivery.
Delivery and installation fees may be invoiced separately and are payable upon completion, unless otherwise agreed in writing.
All prices are in Australian dollars and include GST unless stated otherwise.
Ownership of all goods remains with Southern Cross Saunas until full payment is received.
4. Delivery, Installation, and Site Requirements
Delivery dates are estimates only and depend on supplier lead times, weather conditions, and logistics.
We will provide an approximate installation timeframe once all payments have cleared.
You are responsible for ensuring:
The site is prepared and accessible;
Any required council or strata approvals are in place;
Power supply and clear workspace are available.
Delays caused by inaccessible or unprepared sites may incur additional charges.
5. Quality and Warranty
We warrant that all goods and services will:
Be of acceptable quality;
Match their description;
Be fit for purpose within normal commercial use.
Our liability for defective goods or workmanship is limited to (at our discretion):
Repair;
Replacement; or
Refund for the affected portion of work.
This warranty does not cover damage caused by misuse, improper maintenance, or unauthorised modification.
6. Variations and Additional Work
If you request changes to the project after signing the order, or if unexpected site conditions require extra work, we will provide a written variation quote before proceeding.
No additional costs will be charged without your written approval.
7. Delays and Force Majeure
We are not responsible for delays caused by events beyond our reasonable control, including:
Extreme weather;
Supplier or freight delays;
Power outages;
Changes requested by you;
Site inaccessibility or safety issues.
We will keep you informed and reschedule as soon as possible.
8. Non-Payment and Default
If payment is not made by the agreed date, we may:
Suspend work or delivery until payment is received;
Charge interest at 3% above the NAB base rate on overdue amounts;
Retain ownership of any goods not yet paid for;
Recover reasonable costs (including legal fees) associated with debt recovery.
9. Your Responsibilities
You agree to:
Provide accurate site information and measurements;
Prepare the site as advised;
Ensure safe working conditions for our team;
Allow reasonable access to complete installation.
We are not liable for loss or damage resulting from inaccurate information, delays in other contractors’ work, or unsafe site conditions.
10. Intellectual Property
All plans, drawings, designs, and documents created by Southern Cross Saunas remain our intellectual property and cannot be copied or used without written permission.
11. Cancellations
Once a project has commenced, cancellation is subject to the following:
You will be charged for all work performed, materials ordered, and costs incurred up to the cancellation date.
Deposits may be retained to cover initial expenses and lost production time.
If we agree to cancel after production has begun, any balance owing must be paid within 7 days.
12. Limitation of Liability
Our total liability is limited to the amount paid for the goods or services giving rise to the claim.
We are not liable for:
Loss of profits, income, or business opportunities;
Consequential or indirect loss;
Damage caused by third parties or failure to follow care instructions.
Nothing in these Terms limits our liability for death, personal injury, or gross negligence.
13. Amendments
We may update these Terms and Conditions as required by law or to reflect changes in our operations.
The latest version will always be available on our website.
14. Governing Law
This agreement is governed by the laws of New South Wales, Australia, and both parties submit to the jurisdiction of the NSW courts.
15. Contact Us
Southern Cross Saunas
Operated by David Andrews, Sole Trader (ABN 32 115 032 815)
Email: info@southerncrosssaunas.com.au
Address: 66 Swan Street, Morpeth NSW 2321
Phone: 0297352363
Effective Date: 12 November 2025
This agreement sets out the terms under which Southern Cross Saunas, operated by David Andres as a sole trader (ABN 32 115 032 815) (“Southern Cross Saunas”, “we”, “our”, or “us”), provides products and installation services to commercial clients (“you”, “your”).
By accepting a quote, paying a deposit, or confirming an order, you agree to these Terms and Conditions.
1. Scope of Agreement
These Terms apply to all goods and services supplied by Southern Cross Saunas to business customers, including the manufacture, delivery, and installation of saunas or related products.
If you are purchasing as a consumer, our Consumer Terms and Conditions will apply instead.
2. Quotes and Contracts
A Quote outlines the estimated cost of your project, including design, materials, and installation.
Once you approve the quote in writing or pay a deposit, a binding contract is formed.
A detailed Order Confirmation Form will confirm the final specifications and pricing.
Changes requested after approval may affect cost and delivery timelines.
We encourage you to carefully review the quote before proceeding.
3. Deposits and Payments
Payment is made in stages as follows:
40% deposit – payable upon acceptance of the Quote. This deposit becomes non-refundable once procurement of materials or design and engineering work has commenced.
30% progress payment – payable upon commencement of production.
30% final payment – payable prior to delivery.
Delivery and installation fees may be invoiced separately and are payable upon completion, unless otherwise agreed in writing.
All prices are in Australian dollars and include GST unless stated otherwise.
Ownership of all goods remains with Southern Cross Saunas until full payment is received.
4. Delivery, Installation, and Site Requirements
Delivery dates are estimates only and depend on supplier lead times, weather conditions, and logistics.
We will provide an approximate installation timeframe once all payments have cleared.
You are responsible for ensuring:
The site is prepared and accessible;
Any required council or strata approvals are in place;
Power supply and clear workspace are available.
Delays caused by inaccessible or unprepared sites may incur additional charges.
5. Quality and Warranty
We warrant that all goods and services will:
Be of acceptable quality;
Match their description;
Be fit for purpose within normal commercial use.
Our liability for defective goods or workmanship is limited to (at our discretion):
Repair;
Replacement; or
Refund for the affected portion of work.
This warranty does not cover damage caused by misuse, improper maintenance, or unauthorised modification.
6. Variations and Additional Work
If you request changes to the project after signing the order, or if unexpected site conditions require extra work, we will provide a written variation quote before proceeding.
No additional costs will be charged without your written approval.
7. Delays and Force Majeure
We are not responsible for delays caused by events beyond our reasonable control, including:
Extreme weather;
Supplier or freight delays;
Power outages;
Changes requested by you;
Site inaccessibility or safety issues.
We will keep you informed and reschedule as soon as possible.
8. Non-Payment and Default
If payment is not made by the agreed date, we may:
Suspend work or delivery until payment is received;
Charge interest at 3% above the NAB base rate on overdue amounts;
Retain ownership of any goods not yet paid for;
Recover reasonable costs (including legal fees) associated with debt recovery.
9. Your Responsibilities
You agree to:
Provide accurate site information and measurements;
Prepare the site as advised;
Ensure safe working conditions for our team;
Allow reasonable access to complete installation.
We are not liable for loss or damage resulting from inaccurate information, delays in other contractors’ work, or unsafe site conditions.
10. Intellectual Property
All plans, drawings, designs, and documents created by Southern Cross Saunas remain our intellectual property and cannot be copied or used without written permission.
11. Cancellations
Once a project has commenced, cancellation is subject to the following:
You will be charged for all work performed, materials ordered, and costs incurred up to the cancellation date.
Deposits may be retained to cover initial expenses and lost production time.
If we agree to cancel after production has begun, any balance owing must be paid within 7 days.
12. Limitation of Liability
Our total liability is limited to the amount paid for the goods or services giving rise to the claim.
We are not liable for:
Loss of profits, income, or business opportunities;
Consequential or indirect loss;
Damage caused by third parties or failure to follow care instructions.
Nothing in these Terms limits our liability for death, personal injury, or gross negligence.
13. Amendments
We may update these Terms and Conditions as required by law or to reflect changes in our operations.
The latest version will always be available on our website.
14. Governing Law
This agreement is governed by the laws of New South Wales, Australia, and both parties submit to the jurisdiction of the NSW courts.
15. Contact Us
Southern Cross Saunas
Operated by David Andrews, Sole Trader (ABN 32 115 032 815)
Email: info@southerncrosssaunas.com.au
Address: 66 Swan Street, Morpeth NSW 2321
Phone: 0297352363
© Southern Cross Saunas 2025
Navigation
Socials & Messaging
Always in Touch